A reflective report is a document that summarizes and evaluates a person's thoughts, feelings, and experiences on a specific topic or project. It is a way for individuals to reflect on their learning and development, and to document their progress and achievements.
There are many different ways to structure a reflective report, but a common template includes the following elements:
Introduction: This section should provide context for the report, outlining the purpose and scope of the reflection. It should also explain the process of reflection, including how the individual gathered and analyzed their thoughts and experiences.
Body: This section should be the main focus of the report, and should contain the individual's reflections on the topic or project. It should include a detailed description of their experiences and any insights or learning that resulted from those experiences.
Conclusion: This section should summarize the key points of the report and highlight any major takeaways or lessons learned. It should also discuss any future plans or goals that may have been influenced by the reflection.
Recommendations: If applicable, this section should provide recommendations for future action based on the individual's reflection. This could include recommendations for future projects, strategies for learning and development, or suggestions for improvement.
Appendices: This section should include any additional materials that may be relevant to the report, such as documents, photographs, or other supporting evidence.
Overall, a reflective report template should be tailored to the specific needs and goals of the individual conducting the reflection. It should provide a structured framework for organizing and presenting their thoughts and experiences, and should be used as a tool for reflection, learning, and personal development.
Nominated Subcontractors Definition
This mixing of responsibilities between the employer and main contractor for the performance of a nominated subcontractor leads to frequent disputes. However, the procedure was not followed in this case. Either things have either changed since then, or not all forms of contract take this view. This follows a tender process in which the contractor is given the opportunity to consult with the principal agent during the scrutinising of tenders. Instead the engineer on behalf of St Modwen Developments, "the Employer" obtained quotations from specialist subcontractors for design, supply and installation of the specialist work and the Contractor was given an instruction to place an order with the chosen subcontractor. The contract administrator asked Nelson Tectonics to submit its price to the Contractor, which Nelson Tectonics did, advising the Contractor that the price had been agreed with the contract administrator. Analytics cookies collect anonymised information such as the number of site visitors or most popular pages.
This translates to fewer permanent personnel and less equipment on hand. In those circumstances, the consultant provides the administration and coordination on behalf of the client. For all intents and purposes, this subcontractor is treated as a domestic subcontractor. Figure 1 construction management: concrete construction bridge construction:How to become a bridge engineer The Flakiness Index of aggregates is the percentage by weight of particles whose least dimension thickness is less than three- fifths 0. Why Should You Use a Subcontractor? Minimize Labour and Overhead Costs You can also keep your overhead costs down by using subcontractors.
The quality of aggregates can greatly affect the strength and durability of concrete. Stressing concrete has various benefits, such as increasing concrete members' capacity, reducing the concrete member section, and increasing the span lengths for structures such as bridges and buildings. In effect, the client lists a minimum of three subcontractors they have deemed as acceptable to carry out the works. Personalisation cookies collect information about your website browsing habits and offer you a personalised user experience based on past visits, your location or browser settings. This is not the case where the client enters into a separate direct contract for such work. Under JCT 98, Clause 35. Construction Contracts: Law and Management.
How to Deal with Delay Caused by a Nominated Subcontractor
Working to their current programme, they will not have a contractor procured in time that could place an order for the long lead items, therefore the client has to step in early and place the order themselves. A soundness test will be conducted using La Chatelier's apparatus. Where the Architect has so certified, the Employer may but not obliged to pay such amounts directly to the Nominated Sub-Contractor and deduct the same from any sums due or to become due to the Contractor. The solution of concrete Bulging, offset, or surface irregularities are surface grinding. The Nominated Sub-Contractor is made part of the contracting team being fully involved, if required. Magnesia reacting with water similarly as calcium oxide does.
If Project Manager rejected the Sub-Contractor in the list not based on NEC3 option B 05, Clause 26. It is important to understand the difference between the two as they may have implications for the Employer. During the placing and compacting of concrete, forms may deflect largely in the weak areas. Advantages of Nominated Subcontractor Who is Nominated Subcontractor? Special attendance are the things specific to the particular subcontractor if requests to be provided by the main contractor. The court found that the clause did not meet the.
Diaphragm will be used also to resist stresses that occurs during the post-tensioning process. Projects of Mega Commercial Buildings, Hospitality, Hospitals, etc. The named subcontracting concept requires names of would-be subcontractors to be furnished at the main contract tender stage by the consultants, for the main contractor to issue tender enquiries and for him to select the proposed named subcontractor. If Project Manager rejected the Sub-Contractor in the list based on NEC3 option B 05, Clause 26. The quantity surveyor issued a revised tender which took account of Nelson Tectonics' contract price and which the Contractor agreed. By tying the steel bars together, we ensure that the steel bars will not move from their locations during construction or during the time of concreting.
In many cases, the client may already have a quotation agreed for the works with each subcontractor. Under JCT 05, Clause 3. Accordingly, by engaging a nominated subcontractor, the client gets the assurance that the right party does the specialized works. The Contractor shall not be entitled to any extension of time unless and until the Contractor has established that the determination by the Nominated Sub-Contractor of his own employment is invalid. Nominated Subcontractor is the subcontractor selected in this way. In my opinion, I think that the new Specialist Sub-Contractor appointment procedures had makes it simpler. Pi The main function of diaphragms is to provide a stiffening effect to deck slab in case bridge webs are not situated directly on top of bearings.
Therefore we should always ensure that the forms are appropriately installed, and it is sufficiently supported to resist the concrete during placing and compacting. Prime cost sum PC sum and Provisional sum In Standard Method of Measurements in Sri Lanka — SLS 573:1999 states prime cost as a sum provided for work or services to carry out by a nominated subcontractor. Assistance in resolving early technical issues and In terms of named subcontractors, the client is still able to influence the supply chain list, but this is not absolute like nomination. Such Sub-Contractor as known as Domestic Sub-Contractor. Nominated subcontracting mutually benefits the client and subcontractor. The sum representing such total value less any retention and deductions expressly provided under PAM Sub-Contract 2006 shall be paid by the Contractor to the Nominated Sub-Contractor within seven 7 Days after the Period of Honouring Certificates. Under JCT 05, Clause 3.
